NOTICE TO BIDDERS Notice is hereby given that sealed bids will be received by Princeton, County of Mercer, State of New Jersey on June 12, 2024, at 11:00 A.M. prevailing time at the Princeton Municipal Building, 400 Witherspoon Street, Princeton, New Jersey 08540, at which time and place bids will be opened and read publicly for: Energy and HVAC System Improvements at the Princeton Municipal Building located at 400 Witherspoon Street, Princeton, New Jersey. This contract provides for the removal of existing air‐cooled condensing units and associated refrigerant piping and coils; the installation of new air‐cooled chillers and associated chilled glycol piping, pumps, coils and controls; the installation of a new boiler and associated hot water pumps and controls; the upgrading of controls on existing variable air volume terminals; expanding the existing building management system; replacing light fixtures with new LED fixtures; and associated work as indicated on the plans and in the specifications. Plans, specifications and bid documents are available for download at https://www.princetonnj.gov/Bids.aspx at no cost. A pre-bid meeting will be held on May 20, 2024, at 8:30 A.M. prevailing time at the Princeton Municipal Building. Bids shall be submitted in a sealed envelope, addressed to the Municipal Clerk, Princeton, 400 Witherspoon Street, First Floor, Princeton, New Jersey 08540, and the outside of the envelope must be clearly marked with the name and address of the bidder, and the title of the bid. Each bid shall be accompanied by a certified check, bank cashier's check or bid bond of an amount equal to at least ten percent (10%) of the total bid, but not to exceed $20,000.00, payable to Princeton. Bidders are required to comply with the requirements of N.J.S.A. 10:5-31 et seq. and N.J.A.C. 17:27-1 et seq. Sarah Ocicki Qualified Purchasing Agent 1x, PP, 5/10/24, Fee:$29.26

NOTICE TO BIDDERS Notice is hereby given that sealed proposals will be received by the Township of Hillsborough, Somerset County, New Jersey for the “2024-02 Capital Roadway Paving Project” and opened and read in public in the Court Room at the Township of Hillsborough, 379 South Branch Road, Hillsborough, NJ 08844 on Wednesday, May 29, 2024 at 10:30 a.m. prevailing time. Contract Documents and Drawings for the proposed work, which have been prepared by Township’s Engineering Department, may be inspected by prospective bidders during business hours 8:00 a.m.-4:30 p.m. The Bid consists of site clearing, removal and disposal of existing sidewalk, installation of concrete sidewalk, as well as concrete paver blocks, concrete and Belgium block curb, and other work set out in the specifications. Bidders will be furnished with a copy of the Bid Package and Contract Documents by request upon proper notice and payment of a non-refundable charge of Fifty Dollars ($50.00) payable to Township of Hillsborough, to defray the cost thereof. Proposals must be made on the standard Proposal Forms in the manner designated in the Contract Documents, must be enclosed in sealed envelopes bearing the name and address of the Bidder, and the name of the work on the outside; addressed to Assistant Engineer, Thomas Belanger, Township of Hillsborough; and must be accompanied by a statement of Consent of Surety from a surety company authorized to do business in the State of New Jersey and acceptable to the Township and either a Bid Bond, Certified or Cashier’s Check drawn to the order of the Township of Hillsborough for not less than ten percent (10%) of the amount bid, except that the check need not exceed $20,000.00. The successful bidder is hereby notified that a performance bond for the full amount of the project is required. The right is also reserved to reject any or all bids or to waive any informalities where such informality is not detrimental to the best interest of Township of Hillsborough. The right is also reserved to increase or decrease the quantities specified in the manner designated in the Specifications. The successful bidder shall be required to comply with all required forms listed in the specifications. BY ORDER OF the Mayor and Committee Members of Township of Hillsborough, Somerset County, New Jersey. Dana Margelis, QPA 1x, HB, 5/10/24, Fee:$33.76

NOTICE TO PRINCETON UNIVERSITY COMMUNITY Please take notice that The Trustees of Princeton University has filed an application with the Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, New Jersey, seeking the modification or release of certain restrictions on gifts to Princeton University that may have become unlawful, impracticable, impossible to achieve, or wasteful. The Court is currently set to hear the matter on May 15, 2024, at 10:30 a.m., or at such other date and time set by the Court, by the Honorable Patrick J. Bartels, P.J. Ch., Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, at the Mercer County Civil Court House, 175 South Broad Street, 3rd Floor, Trenton, New Jersey 08608. The following gift is the subject of this application: Name of Gift Proposed Change The Anonymous Student Loan Fund That the restriction in the gift instrument establishing the Anonymous Fund -- that the income be used for the purpose of making loans to undergraduate students at Princeton -- be modified or released, so that the Fund’s income may be used for the following purposes and in the listed order of preference: i. first, consistent with the terms and implementation of the original gift, providing loans to undergraduate Princeton students; ii. second, to support undergraduate scholarships to assist Princeton students with financial need; and iii. third, when funds still remain, to support graduate fellowships to assist Princeton students with financial need. Copies of the Verified Complaint, Brief and Order to Show Cause in this matter may be obtained through the Office of the General Counsel of Princeton University at the address and telephone number set forth below. Any party who wishes to be heard with respect to the proposed change shall file with the Clerk of the Superior Court, Mercer County and serve upon the Office of the General Counsel of Princeton University at the address set forth below, a written answer, an answering affidavit, a motion returnable on the date this matter is scheduled to be heard or other response to this Order to Show Cause and to the relief requested in the Verified Complaint at least fifteen (15) days before the hearing date. Filing shall be made at the following address: Clerk of the Superior Court, Chancery Division, General Equity Part, Mercer County Civil Courthouse, 175 S. Broad St., 3rd Floor, Trenton, New Jersey (mailing address: P.O. Box 8068, Trenton, New Jersey 08650-0068) and must include a filing fee of $175.00, payable to the “Treasurer, State of New Jersey.” Such responding party shall also file with such Chancery Division, General Equity Part by the foregoing date a proof of service of the responsive pleadings upon the Office of the General Counsel of Princeton University. For additional information, please feel free to contact Robert C. Berness, University Counsel, Office of the General Counsel, Princeton University, New South Building, Fourth Floor, Princeton, New Jersey 08544, (609) 258-7604, rberness@princeton.edu. 1x, PP, 5/10/24, Fee:$47.67 Affidavit Fee:$15.00

NOTICE TO PRINCETON UNIVERSITY COMMUNITY Please take notice that The Trustees of Princeton University has filed an application with the Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, New Jersey, seeking the modification or release of certain restrictions on gifts to Princeton University that may have become unlawful, impracticable, impossible to achieve, or wasteful. The Court is currently set to hear the matter on May 15, 2024, at 10:30 a.m., or at such other date and time set by the Court, by the Honorable Patrick J. Bartels, P.J. Ch., Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, at the Mercer County Civil Court House, 175 South Broad Street, 3rd Floor, Trenton, New Jersey 08608. The following gift is the subject of this application: Name of Gift Proposed Change The Bill Fackert ‘36 Student Loan Fund (“The Fackert Fund”) That the restriction in the gift instruments establishing the Fackert Fund -- that the income from the Fackert Fund be used for the purpose of making loans to undergraduate students at Princeton -- be modified or released, so that the Fund’s income may be used for the following purposes and in the listed order of preference: i. first, consistent with the terms and implementation of the original gift, making loans to undergraduate Princeton students; ii. second, to support undergraduate scholarships to assist Princeton students with financial need; and iii. third, when funds still remain, to support graduate fellowships to assist Princeton students with financial need. Copies of the Verified Complaint, Brief, and Order to Show Cause in this matter may be obtained through the Office of the General Counsel of Princeton University at the address and telephone number set forth below. Any party who wishes to be heard with respect to the proposed change shall file with the Clerk of the Superior Court, Mercer County and serve upon the Office of the General Counsel of Princeton University at the address set forth below, a written answer, an answering affidavit, a motion returnable on the date this matter is scheduled to be heard or other response to this Order to Show Cause and to the relief requested in the Verified Complaint at least fifteen (15) days before the hearing date. Filing shall be made at the following address: Clerk of the Superior Court, Chancery Division, General Equity Part, Mercer County Civil Courthouse, 175 S. Broad St., 3rd Floor, Trenton, New Jersey (mailing address: P.O. Box 8068, Trenton, New Jersey 08650-0068) and must include a filing fee of $175.00, payable to the “Treasurer, State of New Jersey.” Such responding party shall also file with such Chancery Division, General Equity Part by the foregoing date a proof of service of the responsive pleadings upon the Office of the General Counsel of Princeton University. For additional information, please feel free to contact Robert C. Berness, University Counsel, Office of the General Counsel, Princeton University, New South Building, Fourth Floor, Princeton, New Jersey 08544, (609) 258-7604, rberness@princeton.edu. 1x, PP, 5/10/24, Fee:$48.27 Affidavit Fee:$15.00

NOTICE TO PRINCETON UNIVERSITY COMMUNITY Please take notice that The Trustees of Princeton University has filed an application with the Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, New Jersey, seeking the modification or release of certain restrictions on gifts to Princeton University that may have become unlawful, impracticable, impossible to achieve, or wasteful. The Court is currently set to hear the matter on May 15, 2024, at 10:30 a.m., or at such other date and time set by the Court, by the Honorable Patrick J. Bartels, P.J. Ch., Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, at the Mercer County Civil Court House, 175 South Broad Street, 3rd Floor, Trenton, New Jersey 08608. The following gift is the subject of this application: Name of Gift Proposed Change The Paul Guenther Student Loan Fund That the restriction in the gifts’ instruments establishing the Guenther Fund -- that the income be used for the purpose of making loans to “deserving” undergraduate students at Princeton -- be modified or released, so that the Fund’s income may be used for the following purposes and in the listed order of preference: i. first, consistent with the terms and implementation of the original gift, providing loans to “deserving” undergraduate Princeton students i.e., students in need of financial assistance; ii. second, to support undergraduate scholarships to assist Princeton students with financial need; and iii. third, when funds still remain, to support graduate fellowships to assist Princeton students with financial need. Copies of the Verified Complaint, Brief, and Order to Show Cause in this matter may be obtained through the Office of the General Counsel of Princeton University at the address and telephone number set forth below. Any party who wishes to be heard with respect to the proposed change shall file with the Clerk of the Superior Court, Mercer County and serve upon the Office of the General Counsel of Princeton University at the address set forth below, a written answer, an answering affidavit, a motion returnable on the date this matter is scheduled to be heard or other response to this Order to Show Cause and to the relief requested in the Verified Complaint at least fifteen (15) days before the hearing date. Filing shall be made at the following address: Clerk of the Superior Court, Chancery Division, General Equity Part, Mercer County Civil Courthouse, 175 S. Broad St., 3rd Floor, Trenton, New Jersey (mailing address: P.O. Box 8068, Trenton, New Jersey 08650-0068) and must include a filing fee of $175.00, payable to the “Treasurer, State of New Jersey.” Such responding party shall also file with such Chancery Division, General Equity Part by the foregoing date a proof of service of the responsive pleadings upon the Office of the General Counsel of Princeton University. For additional information, please feel free to contact Robert C. Berness, University Counsel, Office of the General Counsel, Princeton University, New South Building, Fourth Floor, Princeton, New Jersey 08544, (609) 258-7604, rberness@princeton.edu. 1x, PP, 5/10/24, Fee:$44.89 Affidavit Fee:$15.00

NOTICE TO PRINCETON UNIVERSITY COMMUNITY Please take notice that The Trustees of Princeton University has filed an application with the Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, New Jersey, seeking the modification or release of certain restrictions on gifts to Princeton University that may have become unlawful, impracticable, impossible to achieve, or wasteful. The Court is currently set to hear the matter on May 15, 2024, at 10:30 a.m., or at such other date/time set by the Court, by the Honorable Patrick J. Bartels, P.J. Ch., Superior Court of New Jersey, Chancery Division, General Equity Part, Mercer County, at the Mercer County Civil Court House, 175 South Broad Street, 3rd Floor, Trenton, New Jersey 08608. The following gift is the subject of this application: Name of Gift Proposed Change The Norman Drummond Campbell ’30 Student Loan Fund That the restriction in the gifts’ instruments establishing the Campbell Fund -- that the income be used for the purpose of making loans to “needy, worthy” undergraduate Princeton students -- be modified or released, so that the Fund’s income may be used for the following purposes and in the listed order of preference: i. first, consistent with the terms and implementation of the original gift, making loans to “needy, worthy” undergraduate Princeton students, i.e., students in need of financial assistance; ii. second, to support undergraduate scholarships to assist Princeton students with financial need; and iii. third, when funds still remain, to support graduate fellowships to assist Princeton students with financial need. Copies of the Verified Complaint, Brief and Order to Show Cause in this matter may be obtained through the Office of the General Counsel of Princeton University at the address and telephone number set forth below. Any party who wishes to be heard with respect to the proposed change shall file with the Clerk of the Superior Court, Mercer County and serve upon the Office of the General Counsel of Princeton University at the address set forth below, a written answer, an answering affidavit, a motion returnable on the date this matter is scheduled to be heard or other response to this Order to Show Cause and to the relief requested in the Verified Complaint at least fifteen (15) days before the hearing date. Filing shall be made at the following address: Clerk of the Superior Court, Chancery Division, General Equity Part, Mercer County Civil Courthouse, 175 S. Broad St., 3rd Floor, Trenton, New Jersey (mailing address: P.O. Box 8068, Trenton, New Jersey 08650-0068) and must include a filing fee of $175.00, payable to the “Treasurer, State of New Jersey.” Such responding party shall also file with such Chancery Division, General Equity Part by the foregoing date a proof of service of the responsive pleadings upon the Office of the General Counsel of Princeton University. For additional information, please feel free to contact Robert C. Berness, University Counsel, Office of the General Counsel, Princeton University, New South Building, Fourth Floor, Princeton, New Jersey 08544, (609) 258-7604, rberness@princeton.edu. 1x, PP, 5/10/24, Fee:$46.45 Affidavit Fee:$15.00

OROUGH OF PENNINGTON ORDINANCE 2024-10 AN ORDINANCE ACCEPTING GIFT OF MEMORIAL GAZEBO AND RELATED IMPROVEMENTS TO LAND OWNED BY THE BOROUGH AT THE CORNER OF BROEMEL PLACE AND KNOWLES STREET, IN HONOR OF THE YEARS OF SERVICE TO THIS COMMUNITY BY THE VOLUNTEERS OF THE PENNINGTON FIRST AID SQUAD The foregoing ordinance was finally adopted at a meeting of the Pennington Borough Council on May 6, 2024. The ordinance is posted on the bulletin board in Borough Hall and on the Borough web-site. Copies are available to the public in the office of the Borough Clerk Betty Sterling Borough Clerk 1x, HV, 5/10/24, Fee:$10.00 Affidavit Fee:$15.00

PUBLIC NOTICE AN ORDINANCE OF THE BOROUGH OF HOPEWELL, COUNTY OF MERCER, NEW JERSEY, REGARDING EXCAVATIONS AND ROAD OPENINGS IN MUNICIPAL STREETS, AND AMENDING CHAPTER 8 OF “THE REVISED GENERAL ORDINANCES OF THE BOROUGH OF HOPEWELL, 1975” Notice is hereby given that the above entitled Ordinance No. 885 has been finally passed at a duly convened meeting of the Borough Council of the Borough of Hopewell, in the County of Mercer, held on the 2nd day of May, 2024. Regina M. Toth Borough Clerk 1x, HV, 5/10/24, Fee:$9.00

PUBLIC NOTICE Attention: Gloucester City Seniors Citizens Come out to play cards, bingo and have coffee with fellow residents. Every Tuesday, 9am-2pm at Gloucester Heights Fire Hall/Community Center, 230 Nicholson Road. Cost $2.00 per person Vanessa L. Little City Clerk Dated:3/20, 4/3,17, 5/1,15,29/24 Prt's Fee:$32.40

PUBLIC NOTICE BOND ORDINANCE STATEMENT AND SUMMARY The bond ordinance, the summary terms of which are included herein, has been finally adopted by the Township of Hillsborough, in the County of Somerset, State of New Jersey on April 30, 2024 and the 20 day period of limitation within which a suit, action or proceeding questioning the validity of such bond ordinance can be commenced, as provided in the Local Bond Law, has begun to run from the date of the first publication of this statement. Copies of the full bond ordinance are available at no cost and during regular business hours at the Clerk's office for members of the general public who request the same. The summary of the terms of such bond ordinance follows: Title: BOND ORDINANCE PROVIDING FOR VARIOUS TOWNSHIP-WIDE ROAD IMPROVEMENTS IN AND BY THE TOWNSHIP OF HILLSBOROUGH, IN THE COUNTY OF SOMERSET, NEW JERSEY, APPROPRIATING $9,000,000 THEREFOR AND AUTHORIZING THE ISSUANCE OF $8,550,000 BONDS OR NOTES OF THE TOWNSHIP TO FINANCE PART OF THE COST THEREOF Purpose(s): Township-wide road resurfacing and overlay program for various streets throughout the Township, all as set forth on a list on file in the office of the Township's Engineering Department, including all work and materials necessary therefor and incidental thereto Appropriation: $9,000,000 Bonds/Notes Authorized: $8,550,000 Grants (if any) Appropriated: N/A Section 20 Costs: $1,500,000 Useful Life: 10 years Sarah Brake Hillsborough Township Clerk 1x, HB, 5/10/24, Fee:$24.76

PUBLIC NOTICE BOROUGH OF HOPEWELL COUNTY OF MERCER CALENDAR YEAR 2024 ORDINANCE TO EXCEED THE MUNICIPAL BUDGET APPROPRIATION LIMITS AND TO ESTABLISH A CAP BANK (N.J.S.A. 40A: 4-45.14) Notice is hereby given that the above entitled Ordinance No. 884 has been finally passed at a duly convened meeting of the Borough Council of the Borough of Hopewell, in the County of Mercer, held on the 2nd day of May, 2024. Regina M. Toth Borough Clerk 1x, HV, 5/10/24, Fee:$10.00

PUBLIC NOTICE COUNTY OF MERCER, STATE OF NEW JERSEY ORDINANCE NO. 882 AN ORDINANCE REPLACING CHAPTER XIX OF THE “REVISED GENERAL ORDINANCES OF THE BOROUGH OF HOPEWELL, 1975, AS AMENDED, AND ENTITLED “STORM WATER MANAGEMENT” Notice is hereby given that the above entitled Ordinance No. 882 has been finally passed at a duly convened meeting of the Borough Council of the Borough of Hopewell, in the County of Mercer, held on the 2nd day of May, 2024. Regina M. Toth Borough Clerk 1x, HV, 5/10/24, Fee:$10.00

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/16/2024 at which time the bid proposals submitted will be downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Route 133, CR 571 to Route 33, Contract No. 000243020, Pavement Preservation, East Windsor Township, Mercer County Federal Project No: 0133300 UPC NO: 243020 DP No: 24113 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected ( BUT NOT OBTAINED) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, 4/25, 5/3, 5/10/24, HV, PP, Fee:$257.46

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/16/24, downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Maintenance Movable Bridge and Tunnel Repair Contract, Statewide - 2024, Various Locations Statewide 100% State Funded DP No: 24424 Bidders are required to comply with the requirements of N.J.S.A. 10:5-31 (P.L 1975, c. 127); N.J.A.C. 17:27. Pursuant to N.J.S.A. 19:44A-20.19, contractors must provide a Certification and Disclosure of Political Contribution Form prior to contract award. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. Plans, specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected ( BUT NOT OBTAINED) by contracting organizations at our Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, 4/26, 5/3, 5/10, Fee:$131.07

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/16/24, downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Maintenance Roadway Contract C315, NJ 440 NB &NJ 35 NB in Middlesex and Monmouth Counties and Various Locations in Hunterdon, Middlesex and Somerset Counties 100% State Funded DP No: 24405 Bidders are required to comply with the requirements of N.J.S.A. 10:5-31 (P.L 1975, c. 127); N.J.A.C. 17:27. Pursuant to N.J.S.A. 19:44A-20.19, contractors must provide a Certification and Disclosure of Political Contribution Form prior to contract award. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. Plans, specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected (BUT NOT OBTAINED) by contracting organizations at our Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, 4/26, 5/3, 5/10/24, Fee:$114.69

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/21/24 downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Drainage Restoration Contract, Central - 2024-1, NJ 13, NJ 18, NJ 18 SPUR, NJ 26, NJ 27, US 22, Hunterdon, Mercer, Middlesex, Monmouth, Ocean, Somerset, and Warren Counties Federal Project No: D00S (791) DP No: 24419 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor, Division of Wage and hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, any addenda to the specifications, and bidding information may be inspected (BUT NOT OBTAINED) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, HB, PP, 5/3, 5/10, 5/17/24, Fee:$393.21

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/23/24 , downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Maintenance Sign and Sign Structures Repair Contract, Central – 2024, Various Locations, Hunterdon, Mercer, Middlesex, Monmouth, Ocean, Somerset and Warren (South of Route 57) Counties 100% State Funded DP No: 24458 Bidders are required to comply with the requirements of N.J.S.A. 10:5-31 (P.L 1975, c. 127); N.J.A.C. 17:27. Pursuant to N.J.S.A. 19:44A-20.19, contractors must provide a Certification and Disclosure of Political Contribution Form prior to contract award. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. Plans, specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected ( BUT NOT OBTAINED ) by contracting organizations at our Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, HB, PP, 5/3, 5/10, 5/17/24, Fee:$337.05

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/23/24 at which time the bid proposals submitted will be downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Route 82 from Rt 124 to Rt 439; Route 93 from Rt 1&9 to Van Nostrand Ave., Contract No. 000234020, Pavement Preservation, Townships of Springfield, Union, Boroughs of Ridgefield, Palisades Park, Leonia; City of Englewood, Union and Bergen Counties Federal Project No: 0093300 UPC NO: 234020 DP No: 24111 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected (BUT NOT OBTAINED) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, PP, 5/3, 5/10, 5/17/24, Fee:$142.77

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 5/30/24 at which time the bid proposals submitted will be downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Route 31, Parkway Avenue (CR 634) to Crest Avenue, Contract No. 001234080, Townships of Ewing and Hopewell, Mercer County Federal Project No: 0031343 UPC NO: 234080 DP No: 24118 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor and Workforce Development, Division of Wage and Hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, and bidding information may be inspected ( BUT NOT OBTAINED ) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, HV, PP, 5/10, 5/17, 5/24/24, Fee:$257.46

PUBLIC NOTICE NOTICE OF MEETING OF THE ADVISORY COMMITTEE ON AFFORDABLE HOUSING, HUMAN SERVICES, & RACIAL, SOCIAL & ECONOMIC EQUITY NOTICE IS HEREBY given that the Advisory Committee on Affordable Housing, Human Services, & Racial, Social & Economic Equity will hold their inaugural meeting on Thursday, May 16, 2024 at 6:00 p.m., in person at Monument Hall, Main Meeting Room, 1 Monument Drive, Princeton, NJ. This is an open public meeting. Rayna E. Harris Municipal Clerk 1x, PP, 5/10/24, Fee:$9.00

PUBLIC NOTICE Princeton Cemetery of Nassau Presbyterian Church The annual meeting of the lot owners will be held on Thursday, May 23, 2024 at 5:00PM at the Princeton Cemetery at 29 Greenview Avenue, Princeton, New Jersey. Timothy Brown, Chairman Cemetery Committee of Nassau Presbyterian Church 1x, PP, 5/10/245, Fee:$6.84, Affidavit Fee:$15.00

PUBLIC NOTICE PROFESSIONAL SERVICES (2024)—NOTICE OF CONTRACT AWARDS Notice of Award for Professional Service Contracts (Local Public Contracts Law) The Bellmawr Redevelopment Agency has awarded contracts without competitive bidding as a professional service pursuant to N.J.S.A. 40A:11-5(1)(a)(i), but rather through a publicized Request for Proposal <RFP> process. The contracts and the authorizing resolutions are on file and available for public inspection in Bellmawr Borough Hall, located at 21 East Browning Road, Bellmawr, New Jersey, 08031. Auditor Awarded to: Bowman & Company Duration: thru 12/31/2024 Nature and Type of Contract: Auditing / Financial Services Amount of Contract: progress billing General Engineer Awarded to: Remington & Vernick Duration: thru 12/31/2024 Nature and Type of Contract: General Engineering Services Amount of Contract: progress billing General Planner Awarded to: Turek Consulting Duration: thru 12/31/2024 Nature and Type of Contract: Civil/Architectural/Landscape- Planning Services A mount of Contract: progress billing Solicitor Awarded to: McKenna Law Offices Duration: thru 12/31/2024 Nature and Type of Contract: Agency Solicitor / legal Services Amount of Contract: progress billing Special Counsel- Contracts / Negotiations Awarded to: Archer Greiner Law Offices Duration: thru 12/31/2024 Nature and Type of Contract: legal counsel for “contracts / leases” Amount of Contract: progress billing Special Counsel- Environmental Matters Awarded to: Archer Greiner Law Offices Duration: thru 12/31/2024 Nature and Type of Contract: legal counsel for “environmental matters” Amount of Contract: progress billing Traffic Engineer Awarded to: Bowman, McMahon Associates Duration: thru 12/31/2024 Nature and Type of Contract: engineering/planning for traffic related matters Amount of Contract: progress billing Dated:5/8/24 Prt's Fee:$33.60 Affidavit Fee:$5.00

SHERIFF'S SALE By virtue of a Writ of execution, to me directed, issued out of the SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, CAMDEN COUNTY, DOCKET NO. F00177323 at Public Venue on WEDNESDAY the 5th Day of JUNE, 2024 A.D. at 12 o'clock, LOCAL TIME, noon of said day, at 520 MARKET ST, CAMDEN, NJ 08102 CAMDEN CITY COUNCIL CHAMBERS ON 2ND FLOOR. The property to be sold is located in the TOWNSHIP OF GLOUCESTER in the County of CAMDEN and State of New Jersey. Commonly known as: 10 BERKSHIRE RD, SICKLERVILLE, NJ 08081 Tax Lot(s): 6, in Block: 16902 Dimensions: 55X103 Nearest Cross Street: WILTSHIRE ROAD Estimate upset bid amount: $135,000.00, plus any additional sums as ordered by the court Occupancy Status: Owner *SUBJECT TO ANY UNPAID TAXES, MUNICIPAL LIENS OR OTHER CHARGES, AND ANY SUCH TAXES, CHARGES, LIENS, INSURANCE PREMIUMS OR OTHER ADVANCES MADE BY PLAINTIFF PRIOR TO THIS SALE. ALL INTERESTED PARTIES ARE TO CONDUCT AND RELY UPON THEIR OWN INDEPENDENT INVESTIGATION TO ASCERTAIN WHETHER OR NOT ANY OUTSTANDING INTEREST REMAIN OF RECORD AND/OR HAVE PRIORITY OVER THE LIEN BEING FORECLOSED AND, IF SO THE CURRENT AMOUNT DUE THEREON. - 2024 Qtr 2 Due: 05/01/2024 $699.61 OPEN - Sewer: Gloucester Twp. Sewer Dept. 401 Landing Rd Blackwood NJ 08012 856-227-8666 Acct: 20113 0 04/01/2024 – 06/30/2024 $46.00 OPEN AND DUE 04/15/2024 $46.00 OPEN PLUS PENALTY; OWED IN ARREARS - CCMUA: CCMUA 1645 Ferry Ave. Camden, NJ 08104 856-541-3700 Acct: 150150076 03/01/2024 – 05/31/2024 $88.00 OPEN AND DUE 04/15/2024 $176.00 OPEN PLUS PENALTY; OWED IN ARREARS For sale information, please visit Auction at www.Auction.com or call (800) 280- 2832. THE SHERIFF RESERVES THE RIGHT TO ADJOURN THIS SALE WITHOUT FURTHER NOTICE BY PUBLICATION. Surplus Money: If after the sale and satisfaction of the mortgage debt, including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person's claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. The judgment sought to be satisfied by the sale is: "APPROXIMATELY" $134,457.41 TWENTY PERCENT DEPOSIT REQUIRED Seized as the property of TODD J. MILLER; MONIQUE E. WHITE, defendant(s), and taken in execution of SECURITIZED ASSET BACKED RECEIVABLES LLC TRUST 2006-NCl, MORTGAGES PASS-THROUGH CERTIFICATES, SERIES 2006-NCl, U.S. BANK NATIONAL ASSOCIATION AS TRUSTEE, plaintiff GILBERT L. "Whip" WILSON SHERIFF Sheriff's Number: 24000917 DATED: 5/8, 5/15, 5/22, 5/29/2024 Attorney: RAS CITRON LLC 130 CLINTON ROAD SUITE 202 FAIRFIELD, NJ 07004 Prt’s Fee:$156.24 Affidavit Fee:$5.00

SHERIFF'S SALE By virtue of a Writ of execution, to me directed, issued out of the SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, CAMDEN COUNTY, DOCKET NO. F002785815 at Public Venue on WEDNESDAY the 5th Day of JUNE, 2024 A.D. at 12 o'clock, LOCAL TIME, noon of said day, at 520 MARKET ST, CAMDEN, NJ 08102 CAMDEN CITY COUNCIL CHAMBERS ON 2ND FLOOR. The property to be sold is located in the BOROUGH OF CLEMENTON in the County of CAMDEN and State of New Jersey. Commonly known as: 245 GIBBSBORO ROAD, CLEMENTON NJ 08021 Tax Lot(s): 14, in Block: 38 Dimensions (Approx.): 125 X 150 Nearest Cross Street: WHITE HORSE PIKE Upset Amount: $216,000.00 + any commissions assigned by the Sheriff. *Note this upset price is subject to increase as of the date of the sale and you will need to contact the sheriff or plaintiff's counsel for the upset as it exists on the date of sale. Occupancy: Said property is occupied. *Taxes - at time of inquiry - taxes paid through 1st quarter 2024; *Water-at the time of inquiry -$-199.99; * Sewer - at the time of inquiry- $-109.42; *CCMUA - at the time of inquiry - paid to date; (XX) Subject to: If property is located in a Homeowner's Association, then it is sold subject to any assessments and other fees which may be responsibility of new owner under NJ Supreme Court case of Highland Lakes Country Club & Community Association v. Franzino, (XX) Subject to: If property is located in a Condominium Association, then it may be sold subject to a 6-month limited priority lien of the condo association; (XX) Subject to: *If the subject property is part of an age restricted community, you must be 55 and older and intend to reside in the property or you may be precluded membership in the Community. *Also subject to subsequent taxes, water and sewer plus interest through date of payoff. A FULL LEGAL DESCRIPTION OF THE PREMISES CAN BE FOUND IN THE OFFICE OF THE SHERIFF OF CAMDEN COUNTY. THE SHERIFF HEREBY RESERVES THE RIGHT TO ADJOURN THIS SALE WITHOUT FURTHER NOTICE BY PUBLICATION. Surplus Money: If after the sale and satisfaction of the mortgage debt, including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person's claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. The judgment sought to be satisfied by the sale is: "APPROXIMATELY" $221,460.25 TWENTY PERCENT DEPOSIT REQUIRED Seized as the property of BLANCHE FANELLI; WELLS FARGO BANK, N.A., defendant(s), and taken in execution of U.S. BANK NATIONAL ASSOCIATION AS LEGAL TITLE TRUSTEE FOR TRUMAN 2016 SC6 TITLE TRUST, plaintiff GILBERT L. "Whip" WILSON SHERIFF Sheriff's Number: 22002755 DATED: 5/8, 5/15, 5/22, 5/29/2024 Attorney: ROMANO GARUBO & ARGENTIERI 52 NEWTON AVENUE P.O. BOX 456 WOODBURY, NJ 08096 Prt's Fee:$154.56 Affidavit Fee:$5.00

SHERIFF'S SALE By virtue of a Writ of execution, to me directed, issued out of the SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, CAMDEN COUNTY, DOCKET NO. F00653521 at Public Venue on WEDNESDAY the 15th Day of MAY, 2024 A.D. at 12 o'clock, LOCAL TIME, noon of said day, at 520 MARKET ST, CAMDEN, NJ 08102 CAMDEN CITY COUNCIL CHAMBERS ON 2ND FLOOR. The property to be sold is located in the TOWNSHIP OF WINSLOW in the County of CAMDEN and State of New Jersey. Commonly known as: 157 Norcross Road, Berlin (Winslow Twp)., NJ 08009 TAX LOT 14.03, BLOCK 4106 Approximate dimensions: 4,228 sq ft Nearest Cross Street: NEW BROOKLYN ROAD The Plaintiff's Upset Bid presently approximates $812,000.00 plus any additional sums entered by the court. Occupancy Status: Owner Occupied. SURPLUS MONEY: If after the sale and satisfaction of the mortgage debt, including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person's claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. ***Subject to UCC FINANCING STATEMENT: ALLEN'S OIL & PROPANE, INC.*** THE SHERIFF HEREBY RESERVES THE RIGHT TO ADJOURN THIS SALE WITHOUT FURTHER NOTICE THROUGH PUBLICATION. The judgment sought to be satisfied by the sale is: "APPROXIMATELY" $809,892.43 TWENTY PERCENT DEPOSIT REQUIRED Seized as the property of DARRELL K WOODS, ET AL., defendant(s), and taken in execution of MCLP ASSET COMPANY, INC., plaintiff GILBERT L. "Whip" WILSON SHERIFF Sheriff's Number: 24000684 DATED: 4/14, 4/24, 5/1/, 5/8/24 Attorney: PLUESE BECKER & SALTZMAN 20000 HORIZON WAY STE 900 MT LAUREL, NJ 08054 Prt's Fee:$105.84    Affidavit Fee:$5.00